A contractor affected by an employer-risk delay may be entitled to an Extension of Time (EOT) and, where the contract or law supports it, additional compensation. If the contractor is responsible for late completion, the employer may seek liquidated damages or other contractual remedies.

These are separate questions. An extension of time protects the completion date, but it does not automatically create a right to recover delay costs.

Al Ramsy Advocates advises developers, contractors, subcontractors and consultants on construction delay claims and construction law in the UAE.

What Is a Construction Delay Claim?

A construction delay occurs when an event affects the planned progress or completion of the works.

However, not every late activity creates a valid delay claim.

A construction delay claim normally requires analysis of:

• what caused the delay;
• who assumed that risk under the contract;
• whether the event affected project completion;
• whether the required notice was issued;
• whether the delay was mitigated; and
• what time or financial relief is available.

There are usually three different forms of relief to consider:

These should not be treated as the same claim.

When Can a Contractor Claim an Extension of Time?

Extension of time claims depend first on the wording of the construction contract.

Common delay events that may support an EOT include:

• late access to the site;
• delayed drawings or instructions;
• employer variations;
• delayed approvals;
• suspension caused by the employer;
• interference by the employer or its other contractors;
• unforeseen events allocated to the employer’s risk; and
• exceptional events covered by the contract.

The contractor must normally prove that the event affected the Time for Completion, not merely that one activity took longer than expected.

For example, a drawing may be issued 20 days late, but if the affected work had sufficient float and project completion was not delayed, a 20-day EOT does not automatically follow.

This is why EOT claims usually require programme and critical-path analysis.

For projects still at contract stage, clear delay and notice clauses should be addressed in the construction contract rather than left until a dispute develops.

Does an EOT Automatically Include Compensation?

No.

This is one of the most important distinctions in delay claims in construction.

An EOT gives additional time. A claim for money requires a separate contractual or legal entitlement.

An event may therefore be:

• time only — EOT but no additional payment;
• time and money — EOT plus compensable prolongation costs; or
• no relief — where the risk remains with the contractor.

The actual contract must be checked before assuming that an employer-caused event automatically produces both time and compensation.

Notice Requirements for Construction Delay Claims

Notice can determine whether a strong claim survives.

Many UAE projects use FIDIC-based contracts, but the exact edition and Particular Conditions matter.

FIDIC 1999

Under the standard 1999 FIDIC claims procedure, Sub-Clause 20.1 generally requires the contractor to give notice within 28 days after becoming aware, or when it should have become aware, of the event or circumstance giving rise to the claim.

The standard form then provides a 42-day period for the detailed claim, subject to the wording of the contract.

FIDIC 2017

The 2017 FIDIC suite uses a different claims procedure.

Sub-Clause 20.2 generally retains the 28-day Notice of Claim, while the fully detailed claim is generally required within 84 days from awareness of the event or circumstance.

The parties frequently amend these provisions.

A project team should therefore never rely on a generic statement that “FIDIC gives 28 days” without checking:

• the FIDIC edition;
• Contract Data;
• Particular Conditions;
• amendments to the claims clause; and
• any project-specific notice requirements.

Why Is the Notice Deadline Important?

The Panther Real Estate Development LLC v Modern Executive Systems Contracting LLC case before the DIFC Court of Appeal demonstrates the importance of contractual time bars.

In that case, the court treated the contractual 28-day notice requirement as a condition precedent to the contractor’s EOT and additional-payment entitlement.

The decision concerned the wording of the particular contract before the DIFC Courts. It should not be treated as a statutory rule imposing a universal 28-day period on every UAE construction contract.

The practical lesson is simpler: read and follow the actual notice clause from the start of the delay event.

How Do You Prove a Construction Delay?

A contractor does not prove a delay claim simply by showing that the project finished late.

The claim should establish a clear connection between:

Delay event → affected activity → critical path impact → delayed completion

Important programme evidence can include:

• accepted baseline programme;
• updated programmes;
• progress reports;
• site diaries;
• instructions and variation orders;
• RFIs;
• drawing registers;
• approval logs;
• correspondence;
• meeting minutes;
• manpower and equipment records; and
• contemporaneous delay notices.

Depending on the dispute, a delay expert may use techniques such as time impact analysis, windows analysis or comparisons between planned and actual progress.

There is no single delay-analysis methodology that automatically applies to every UAE project.

The appropriate method depends on the contract, available records, programme quality and the nature of the delay.

What Happens if Both Parties Caused Delay?

This is usually described as concurrent delay where employer-risk and contractor-risk events affect completion during the same period.

There is no single statutory formula under UAE law stating that every concurrent delay must be treated in the same way.

The result can depend on:

• the contract;
• whether the delays were genuinely concurrent;
• the critical-path evidence;
• each party’s contribution;
• the wording dealing with EOT and compensation; and
• the remedy being claimed.

For example, entitlement to additional time and entitlement to prolongation costs do not necessarily produce the same result.

The contractor should therefore separate:

1. the number of days claimed as an EOT;
2. the period for which additional cost is claimed; and
3. any period for which the employer seeks liquidated damages.

Simply splitting a concurrent period 50/50 is not a general rule under UAE construction law.

Liquidated Damages for Construction Delays

Liquidated damages in construction are agreed amounts payable for specified contractual breaches, commonly late completion.

The current UAE Civil Transactions Law addresses agreed compensation in Article 340.

The parties may agree compensation in advance, but the contractual amount is subject to the statutory rules.

The court may reduce the agreed compensation where the debtor proves that:

• the amount is excessive; or
• the original obligation was partly performed.

The court may also reduce compensation where the creditor’s own fault contributed to the occurrence or increase of the damage. If the creditor’s fault predominates, the court may refrain from awarding the agreed compensation.

A creditor may seek more than the agreed amount where fraud or gross fault is proved.

Any agreement attempting to exclude the operation of Article 340 is ineffective.

Does the Employer Have to Prove the Exact Agreed Amount of Loss?

An agreed damages clause is intended to set the amount contractually in advance.

However, Article 340 expressly gives the court power to adjust that agreed compensation in the circumstances stated in the law.

For a delay dispute, evidence can therefore become important where the contractor argues that:

• the agreed amount is excessive;
• part of the obligation was performed;
• the employer contributed to the delay; or
• the contractual amount should otherwise be adjusted under Article 340.

Construction contracts still referring to Article 390 of the former Civil Code should be reviewed because the current agreed-compensation provision is Article 340.

When Can a Contractor Claim Construction Delay Compensation?

Construction delay compensation is usually claimed where an event for which the employer bears contractual responsibility extends the period during which the contractor must remain on site.

Depending on the contract and evidence, claimed prolongation costs may include items such as:

• additional site staff;
• extended site facilities;
• plant and equipment;
• temporary works;
• utilities;
• insurance;
• supervision;
• security; and
• other time-related project costs.

The contractor must prove both entitlement and quantum.

It is not enough to say that the project was extended by 100 days and multiply normal monthly costs by that period.

The claim should show that:

• the delay event was compensable;
• it actually extended the relevant project period;
• the costs were caused by that delay;
• the amounts were actually incurred or otherwise recoverable; and
• reasonable mitigation was undertaken.

Head-office overheads, financing costs and loss of profit can require separate analysis depending on the contract and evidence.

Where the dispute has already become contentious, construction litigation lawyers can assess both the contractual entitlement and the records supporting the claimed amount.

What Does UAE Law Say About Exceptional Delay Events?

The construction contract remains the starting point, but the current Civil Transactions Law also contains relevant statutory provisions.

Exceptional General Circumstances

Article 829(3) specifically addresses Muqawala contracts where unforeseen general exceptional circumstances disturb the contractual equilibrium between the employer and contractor.

Where its conditions are satisfied, the court may restore the contractual balance through measures that can include:

• extending the execution period;
• increasing or reducing the remuneration; or
• rescinding the contract.

This is a high-threshold statutory mechanism. It should not be treated as a general EOT clause for ordinary project delays.

Force Majeure

Article 236 deals with force majeure where performance of an obligation becomes impossible.

Difficulty, additional expense or ordinary delay does not automatically amount to impossibility.

A project affected by an exceptional event should therefore be analysed under both:

• the specific contract provisions; and
• the applicable statutory rules.

What Evidence Should Be Kept for an EOT or Delay Claim?

A strong claim is usually built during the project rather than reconstructed years later.

Contractors and employers should preserve:

• the signed construction contract and amendments;
• baseline and revised programmes;
• delay notices;
• EOT applications;
• Engineer determinations;
• variations and instructions;
• daily and weekly site reports;
• correspondence;
• meeting minutes;
• drawing and approval registers;
• procurement records;
• photographs;
• labour and plant records;
• invoices and cost records; and
• documents showing mitigation or acceleration measures.

Contemporary records are particularly important because they show what was happening when the delay occurred, rather than relying solely on later explanations.

How Are Construction Delay Disputes Resolved?

The first step is to follow the dispute procedure in the construction contract.

Depending on the agreement, this may involve:

1. Engineer or contract administrator determination;
2. negotiation;
3. dispute board procedures;
4. settlement discussions;
5. arbitration; or
6. court proceedings.

Large construction disputes frequently involve both legal and technical evidence, including expert delay and quantum analysis.

Where the contract contains a valid arbitration agreement, the dispute may ultimately be handled through construction arbitration in the UAE.

Before starting formal proceedings, the parties should identify separately:

• the EOT entitlement;
• the compensable delay period;
• the claimed prolongation costs;
• any concurrent contractor delay;
• the employer’s liquidated damages claim; and
• whether contractual notice requirements were satisfied.

Keeping those issues separate usually makes the construction delay claim much clearer.

Frequently Asked Questions

What are construction delay claims in the UAE?

Construction delay claims concern time or financial relief arising when events affect project completion. A contractor may seek an extension of time, compensation or both, while an employer may seek liquidated damages for contractor-caused delay.

How long do I have to submit an EOT claim?

The deadline depends on the contract. Standard FIDIC 1999 and 2017 forms generally use a 28-day initial notice period, but their later detailed-claim procedures differ and Particular Conditions frequently amend the standard wording.

Does an extension of time entitle a contractor to additional money?

Not automatically. EOT entitlement and financial compensation are separate. The contractor must identify a contractual or legal basis for recovering delay or prolongation costs.

Can liquidated damages be reduced in the UAE?

Yes. Article 340 of the current UAE Civil Transactions Law allows agreed compensation to be reduced in specified circumstances, including where the amount is excessive, the obligation was partly performed or the creditor contributed to the damage.

What documents are most important in a construction delay claim?

The construction contract, notices, baseline and updated programmes, progress records, instructions, variation documents, correspondence, site records and financial evidence are among the most important documents.

The employer must generally cover treatment until recovery or confirmed disability. If the injury prevents the worker from working, the worker may receive full wages for up to six months, followed by half wages for up to another six months where treatment continues. Permanent disability or death can also result in separate statutory compensation.

Where the accident was caused by negligence or another harmful act, a separate civil compensation claim may also need to be considered.

This article focuses on private-sector workers covered by the federal Labour Law. Different rules may apply to government employees, domestic workers and workers subject to special employment legislation.

Al Ramsy Advocates advises workers and employers on matters involving UAE labour and employment law and construction-related legal disputes.

What Counts as a Construction Injury Under UAE Law?

The UAE Labour Law defines a work injury broadly.

A work injury includes:

• an occupational disease covered by the applicable statutory schedule;
• an injury occurring while the worker is performing work;
• an injury caused by the worker’s employment; and
• certain accidents occurring while travelling directly to or from work, provided there was no interruption or deviation from the normal route.

For construction workers, this can include injuries caused by:

• falls from scaffolding or heights;
• falling materials;
• cranes or lifting equipment;
• excavation or trench collapses;
• machinery;
• electrical hazards;
• fires or explosions;
• unsafe equipment; and
• other construction-site accidents.

The important question is not simply where the accident happened, but whether the construction injury arose during work or because of the work.

An injured worker does not first have to prove employer negligence simply to fall within the statutory work-injury system. However, fault and causation become much more important if a separate civil damages claim is being considered.

What Must an Employer Do After a Construction Accident?

A construction accident triggers specific reporting and protection obligations.

Under Cabinet Resolution No. 33 of 2022, the employer or its legal representative must report a qualifying work injury to the relevant medical authority and competent police station and report the matter to the Ministry of Human Resources and Emiratisation through the designated channels.

MOHRE reporting must generally take place within 48 hours.

The employer must also arrange the worker’s medical treatment and bear the applicable treatment expenses until the worker:

• recovers and can return to work; or
• is medically confirmed to have a disability.

Covered treatment can include hospital care, surgery, medical examinations, medicines, rehabilitation, prosthetic or orthopaedic devices and necessary transport for treatment.

UAE Labour Law also requires employers to provide a safe and appropriate working environment.

For construction businesses, safety responsibilities should therefore be considered alongside wider construction law requirements in the UAE.

How Is Construction Injury Compensation Calculated?

The amount depends on the medical outcome of the injury.

For permanent total disability and death, the compensation is based on 24 months of basic wage, with a minimum of AED 18,000 and maximum of AED 200,000.

Permanent partial disability is calculated using the percentage assigned to the disability under the schedules attached to Cabinet Resolution No. 33 of 2022.

For example, the medical assessment of a permanent partial disability directly affects the statutory calculation.

The employer must generally pay compensation within 10 days after receiving the final medical report establishing the injury or percentage of disability.

Can a Worker Lose the Right to Work Injury Compensation?

In specified circumstances, yes.

Under Article 38 of Federal Decree-Law No. 33 of 2021, statutory work-injury compensation may be denied where the competent investigation proves circumstances such as:

• the worker deliberately injuring themselves;
• injury while under the influence of alcohol, narcotics or psychotropic substances;
• intentional violation of clearly displayed safety instructions;
• wilful misconduct; or
• unjustified refusal to undergo the required medical examination or treatment.

These exclusions require proof through the competent authorities. An employer should not simply assume that compensation is lost because the worker may have made a mistake.

Who Can Be Responsible for a Construction Site Injury?

The employer’s obligations under Labour Law are only one part of the legal analysis.

Construction sites commonly involve several parties, including:

• the injured worker’s employer;
• the main contractor;
• subcontractors;
• engineering or supervisory parties;
• equipment operators;
• equipment owners or suppliers; and
• other entities responsible for the activity that caused the injury.

Not every party on the project becomes liable simply because an accident occurred.

Responsibility depends on matters such as:

• who controlled the relevant work;
• what caused the accident;
• whether a safety obligation was breached;
• whether equipment or machinery was defective;
• whether proper supervision was provided; and
• whether the breach caused or contributed to the injury.

Under Article 253 of Federal Decree-Law No. 25 of 2025, the current UAE Civil Transactions Law, where several persons are responsible for the same harm, liability may be allocated according to their respective contribution, and the court may in appropriate circumstances order equal or joint and several liability.

This is why a serious construction accident UAE claim may require review of the whole site structure rather than only the worker’s employment contract.

Can an Injured Worker Claim Additional Civil Compensation?

Potentially, but it is not automatic.

The statutory compensation available under UAE Labour Law and a civil claim based on a harmful act are legally different issues.

A separate civil claim may need to be considered where the facts establish that another person’s harmful act caused additional compensable damage.

Under the current Federal Decree-Law No. 25 of 2025 Promulgating the Civil Transactions Law, compensation for a harmful act may include the loss actually suffered and loss of profit where they are a natural consequence of the harmful act.

The law also recognises compensation for qualifying moral harm.

This can become important in a serious construction injury involving matters such as:

• permanent disability;
• future loss of earnings;
• long-term medical consequences;
• loss of ability to work;
• substantial financial loss; or
• other proven damage.

However, a worker should not assume that receiving statutory work-injury compensation automatically creates an additional civil damages award.

The civil claim requires its own legal basis, evidence of responsibility, causation and proof of damage.

Where multiple parties may be responsible, the claim also requires analysis of each party’s role.

Al Ramsy’s civil litigation lawyers in the UAE advise on compensation claims and civil liability where serious injury or financial loss has occurred.

Is There a Time Limit for a Civil Injury Claim?

Yes.

For harmful acts governed by the current Civil Transactions Law, Article 258 generally prevents a compensation claim from being heard after three years from the date the injured person became aware of both:

• the damage; and
• the person responsible.

Where the compensation claim arises from a criminal offence and the criminal case remains legally actionable for longer, Article 258 contains a separate rule linking the civil limitation period to the end of the criminal proceedings.

Accidents occurring before the current Civil Transactions Law took effect on 1 June 2026 may require separate analysis under the applicable transitional and former-law rules.

Construction Injury Dubai: What Safety Rules Apply?

A construction injury in Dubai can also engage Dubai-specific construction safety rules.

Dubai Decree No. 19 of 2025 Concerning Safety in Construction Works in the Emirate of Dubai created a specific framework for the Code of Construction Safety Practice.

The Decree applies across Dubai, including:

• Special Development Zones; and
• free zones, including the Dubai International Financial Centre.

Contractors and engineering consultancy firms carrying out construction work must comply with the applicable safety rules, standards, guidelines and obligations contained in the Construction Safety Code.

The framework is intended to protect workers inside and outside construction sites and reduce:

• accidents;
• injuries;
• occupational diseases;
• risks to life;
• property damage; and
• equipment-related risks.

For a serious construction accident Dubai case, compliance with applicable safety requirements may therefore become relevant when investigating how the accident occurred and whether legal duties were breached.

The Dubai safety framework does not itself replace the applicable employment compensation or civil liability rules. The different legal regimes may need to be considered together.

What Should You Do After a Construction Injury?

The immediate priority should always be medical treatment and safety.

After that, the injured worker or family should try to preserve the official and factual record of the accident.

Important steps can include:

1. Obtain medical treatment immediately.
   Make sure the medical record accurately describes how the injury occurred.
2. Report the accident to the employer.
   The employer has separate obligations to notify the relevant authorities.
3. Confirm that the work injury has been officially reported.
   For workers covered by the federal regime, this can include the medical authority, police and MOHRE procedures.
4. Keep copies of medical documents.
   Retain reports, scans, prescriptions, hospital records, rehabilitation records and the final disability assessment.
5. Preserve evidence from the site.
   Photos, videos, witness details and documents can become important later.
6. Keep employment and wage records.
   The employment contract, wage records and basic salary information may be required when compensation is calculated.
7. Do not assume the statutory payment is the only possible claim.
   Serious accidents may require separate assessment of civil liability and other responsible parties.

What Evidence Can Support a Construction Injury Claim?

Evidence should be preserved as early as possible because construction sites change quickly after an accident.

Useful records may include:

• police and accident reports;
• MOHRE work-injury records;
• medical reports;
• disability assessments;
• photographs and videos;
• CCTV where available;
• witness information;
• employment contract;
• wage records;
• site access records;
• toolbox talks and safety instructions;
• PPE records;
• risk assessments;
• equipment inspection records;
• crane, scaffold or machinery records;
• site diaries and incident reports; and
• communications relating to the accident.

For a civil claim, evidence showing how the construction injury happened and who controlled the relevant work can be as important as evidence showing the extent of the injury itself.

Frequently Asked Questions

How much compensation can I receive for a construction injury in the UAE?

The amount depends on the medical outcome. Permanent total disability generally attracts compensation equal to 24 months of basic wage, subject to a minimum of AED 18,000 and maximum of AED 200,000. Permanent partial disability is calculated according to the applicable statutory disability percentage.

Does my employer have to pay my salary after a construction accident?

Where a covered work injury prevents the worker from working, the employer generally pays full wages during treatment for up to six months. If treatment continues, half wages may be payable for up to a further six months, subject to the statutory conditions.

How long does an employer have to report a construction injury?

A covered work injury must generally be reported to MOHRE within 48 hours, together with the other reporting requirements applicable to the medical authority and police.

Can I claim compensation from someone other than my employer?

Potentially. Where another contractor, subcontractor, operator or other party caused or contributed to the injury through a legally actionable harmful act, a separate civil claim may need to be considered. Liability depends on the evidence and each party’s role in causing the accident.

These provisions affect contractor obligations, defective work, contract pricing, variations, agreed damages, termination and decennial liability. They operate alongside the express terms of the construction contract, while certain statutory protections cannot simply be excluded by agreement.

Developers, contractors, consultants and other project parties can also review their position through Al Ramsy’s construction law services in the UAE.

What Is the Current Civil Transaction Law UAE?

The current law is Federal Decree-Law No. 25 of 2025 Promulgating the Civil Transactions Law.

It replaced Federal Law No. 5 of 1985 with effect from 1 June 2026 and now provides the principal federal framework governing contracts, obligations, civil liability and other private-law relationships in the UAE.

For construction, the change is important because many provisions traditionally cited under the former UAE Civil Code now have new article numbers.

The new law generally applies prospectively. Older contracts, events and disputes may therefore continue to engage the former Civil Transactions Law depending on their timing and the transitional provisions.

For construction parties, identifying which version of the law applies should be one of the first steps in reviewing a claim.

This article focuses on construction contracts governed by the federal onshore UAE legal framework.

How Does the Civil Transaction Law UAE Apply to Construction Contracts?

Construction agreements fall within the statutory rules for Muqawala contracts.

Under Article 812, a Muqawala is a contract under which one party undertakes to manufacture something or perform work for consideration paid by the other party.

For a construction project, this can include agreements involving:

• building works;
• engineering works;
• fit-out;
• infrastructure;
• specialist works; and
• other contracted project work.

Article 813 requires the Muqawala contract to specify the subject of the work, its nature and quantity, the method of performance, the completion period and the consideration payable.

In practice, those matters are usually developed through the main agreement together with:

• drawings and specifications;
• Bills of Quantities;
• project programmes;
• scope documents;
• Particular Conditions; and
• other incorporated contract documents.

The civil transaction law UAE framework therefore does not replace the construction contract. Instead, the contract and the statutory provisions need to be read together.

Detailed agreements will normally also regulate payment, variations, extensions of time, delay damages, defects, termination and dispute resolution.

For that reason, construction contracts in the UAE should be reviewed against both their express terms and the current Civil Transactions Law.

Contractor Obligations and Defective Work

The new UAE Civil Transactions Law contains specific rules dealing with contractor performance and problems discovered while the work is being carried out.

Contractor Notice Obligations

Article 816(3) creates an express notification requirement.

If defects appear in materials supplied by the employer, or other circumstances arise that may prevent the work from being properly executed, the contractor must notify the employer immediately.

If the contractor fails to provide the required notice, it may be liable for the consequences resulting from that failure.

On a construction project, this can become relevant where the contractor discovers issues involving:

• employer-supplied materials;
• existing site conditions;
• information affecting execution;
• design-related problems; or
• other circumstances preventing proper performance.

This statutory obligation should be considered alongside any contractual notice provisions.

A FIDIC or bespoke contract, for example, may impose its own deadlines, content requirements and methods for delivering notices.

What Happens if the Work Is Defective?

Article 818 requires the contractor to carry out the work according to the contract and within the agreed period.

If the contractor performs defective work or acts contrary to the contractual requirements, the employer may give notice requiring the contractor to correct the problem within a reasonable period.

If the contractor fails to remedy the breach, the employer may, subject to the requirements of Article 818:

• rescind the contract; or
• appoint another contractor to complete or correct the work at the original contractor’s expense.

The Article also deals with circumstances where more immediate action may be available, including situations where correction is impossible or the contractor’s conduct makes proper completion unlikely.

Termination or replacement should still be considered carefully against the contract itself, including any notice, certification and dispute-resolution procedures.

Construction Prices, Variations and Cost Increases

Pricing disputes are particularly important under lump-sum construction contracts.

Under Article 829, where a Muqawala contract is based on an agreed design for a lump-sum price, the contractor generally cannot demand an increase merely because:

• material prices increased;
• labour became more expensive; or
• other execution costs increased.

Ordinary cost escalation therefore does not automatically transfer to the employer.

What About Variations?

A modification or addition can create a different position where it results from the employer’s fault or is authorised by the employer and the parties agree on the increase in remuneration.

This makes proper variation procedures important.

Project parties should clearly record:

• what changed;
• who instructed it;
• when it was instructed;
• whether the contractor gave the required notice;
• the effect on price; and
• the effect on time.

Exceptional General Circumstances

Article 829 also introduces an important rule for exceptional circumstances.

Where unforeseen general exceptional circumstances fundamentally disturb the financial balance between the employer and contractor, the court may consider restoring the contractual equilibrium.

Depending on the circumstances, this may include:

• extending the performance period;
• increasing the remuneration;
• reducing the remuneration; or
• rescinding the contract.

This does not give contractors a general right to recover every increase in project costs.

The circumstances must satisfy the statutory requirements, and the contract’s existing allocation of risk remains relevant.

Liquidated Damages Under the UAE Civil Transactions Law

Construction agreements often contain predetermined compensation for delay, commonly described as liquidated damages or delay damages.

Under the current UAE Civil Transactions Law, agreed compensation is governed by Article 340, replacing former Article 390.

The parties can agree compensation in advance, but the contractual figure is not necessarily beyond judicial review.

The court may reduce the amount where, for example:

• the agreed compensation is excessive;
• the underlying obligation was partly performed; or
• the creditor contributed to causing or increasing the damage.

Where fraud or gross fault is established, the creditor may also seek compensation above the agreed amount in the circumstances permitted by Article 340.

For construction delay disputes, evidence remains critical.

Relevant records can include:

• baseline and updated programmes;
• extension-of-time notices;
• progress reports;
• instructions;
• variation records;
• correspondence;
• delay analysis; and
• evidence of employer-caused events.

A delay damages provision should therefore not be reviewed in isolation from the actual causes and contractual allocation of delay.

Decennial Liability Under the New UAE Civil Code

The current UAE civil code construction framework retains the important concept of decennial liability, but the applicable article numbers have changed.

The relevant provisions are now Articles 821 to 824 of Federal Decree-Law No. 25 of 2025.

Where the statutory conditions apply, the contractor and relevant engineer may face joint liability for serious problems affecting buildings or other fixed installations, including:

• total collapse;
• partial collapse; or
• defects threatening structural stability or safety.

The liability period generally runs for ten years from delivery of the works.

A claim under the statutory decennial liability regime must generally be brought within three years from the collapse or discovery of the qualifying defect.

Can Decennial Liability Be Excluded?

No.

Article 823 prevents the parties from excluding or limiting the statutory decennial liability.

A construction contract therefore cannot simply reduce this mandatory protection by agreement.

What About Subcontractors?

The current provisions also clarify the relationship between decennial liability and subcontractors.

The statutory decennial liability regime governs the relevant liability to the employer, while a main contractor’s right to recover against a subcontractor is dealt with separately.

The subcontract therefore remains particularly important.

Main contractors should consider clauses dealing with:

• warranties;
• structural defects;
• indemnities;
• liability periods;
• insurance; and
• back-to-back obligations.

Termination of Construction Contracts

The Civil Transactions Law also contains important provisions dealing with the end of a Muqawala contract.

Under Article 834, a Muqawala contract ends when:

• the agreed work is completed;
• the parties mutually agree to end it; or
• it is terminated by court order.

Article 835 allows either party to seek rescission or termination where a supervening impediment prevents performance or completion.

Can an Employer Terminate for Convenience?

Article 836 expressly allows an employer to withdraw from the contract and stop execution before completion.

Where the Article applies, the employer must compensate the contractor for:

• expenses already incurred;
• work already completed; and
• the profit the contractor would have earned if the work had been completed.

The court may reduce the lost-profit element where appropriate, including by taking into account expenses the contractor saved or income earned by using its resources on other work.

This provision can be particularly important where the construction contract does not contain a detailed termination-for-convenience mechanism.

Where the contract does contain one, the contractual wording and statutory position should be reviewed together.

How Do FIDIC Contracts Work With the Civil Transactions Law?

FIDIC forms are widely used in UAE construction projects, but they operate as contractual terms rather than replacing UAE law.

FIDIC Conditions and Particular Conditions may regulate matters including:

• contractor notices;
• variations;
• extensions of time;
• payment certification;
• delay claims;
• employer claims;
• termination; and
• dispute resolution.

Where UAE law governs the agreement, the civil transaction law UAE framework remains relevant even when a FIDIC form is used.

The statutory rules may become particularly important where:

• the contract is silent;
• a provision is unclear;
• a default statutory rule applies; or
• the issue involves a mandatory legal requirement.

Contracts must also be performed consistently with the UAE Civil Transactions Law’s general contractual principles, including good-faith performance.

Parties using standard FIDIC forms should therefore review the Particular Conditions and project-specific amendments rather than assuming the unamended international wording answers every UAE law issue.

A construction contract review can help identify clauses that require adjustment under the current legal framework.

What Should Construction Parties Review Under the New Law?

Developers, contractors, consultants and subcontractors should review existing contract templates and new projects against the updated UAE Civil Transactions Law.

Particular attention should be given to:

1. Applicable law and contract date
   Establish whether Federal Decree-Law No. 25 of 2025 or the former law governs the relevant contract and events.
2. Notice provisions
   Ensure project teams understand both statutory and contractual notice requirements.
3. Defective work procedures
   Review cure periods, replacement-contractor rights and termination procedures against Article 818.
4. Variation and price clauses
   Clearly document instructed changes and distinguish variations from ordinary cost escalation.
5. Liquidated damages
   Review agreed compensation provisions against Article 340 and maintain proper delay records.
6. Decennial liability
   Update contracts that still refer to former Articles 880–883 and review warranties, insurance and subcontract protections.
7. Termination rights
   Check how contractual termination clauses interact with Articles 834–836.
8. Dispute resolution
   Confirm whether disputes are subject to court litigation or arbitration and maintain the documents needed to support a claim.

Where a construction dispute has already developed, the appropriate route may include negotiation, construction litigation in the UAE or arbitration, depending on the agreement and dispute-resolution clause.

Frequently Asked Questions

What is the current civil transaction law UAE?

The current legislation is Federal Decree-Law No. 25 of 2025 Promulgating the Civil Transactions Law. It came into force on 1 June 2026 and replaced Federal Law No. 5 of 1985.

Which UAE Civil Transactions Law provisions apply to construction contracts?

Muqawala contracts, including construction contracts, are principally regulated by Articles 812 to 839, together with general contractual and liability provisions elsewhere in the law.

Does the new UAE Civil Transactions Law apply to old construction contracts?

Not automatically. The law contains rules governing its temporal application, and older contracts, acts or disputes may remain subject to the former Civil Transactions Law depending on the relevant dates and circumstances.

Can a UAE construction contract exclude decennial liability?

No. The statutory decennial liability under Articles 821 to 824 includes mandatory protections that cannot be excluded or limited by contract.

Can a contractor increase a lump-sum price because construction costs increased?

Ordinary increases in labour, materials or other execution costs do not automatically allow the contractor to increase an agreed lump-sum price. Authorised changes and qualifying exceptional general circumstances may produce a different result under Article 829.

.

Whether you are negotiating construction contracts, managing project risks, pursuing construction claims, or responding to disputes, the right legal advice can prevent costly delays and strengthen your legal position. This guide explains the key principles of construction contract law, the legal framework governing construction projects, common contractual issues, and the options available for resolving disputes under UAE law.

What Is Construction Law in the UAE?

Construction law in the UAE is the legal framework that governs construction and engineering projects, including contracts, project execution, compliance, and dispute resolution. It is shaped by federal laws, Emirate-level regulations, and standards such as FIDIC, which define the rights and obligations of the parties involved.

It also covers payment issues, delays, defects, and contract administration. A construction lawyer helps clients manage legal risks and protect their interests throughout the project.

Need Experienced Construction Lawyers in the UAE?

Our construction lawyers advise developers, contractors, consultants, subcontractors, and property owners on construction contracts, FIDIC agreements, construction claims, project disputes, arbitration, litigation, and regulatory compliance throughout the UAE.

Explore Our Construction Law Services

Key Elements of Construction Law

Construction projects involve far more than building work. They rely on clear construction contracts, effective project management, regulatory compliance, and legally enforceable processes for allocating risk and resolving disputes. Understanding these core elements helps reduce uncertainty, improve project outcomes, and minimise the likelihood of costly legal issues.

Construction Contracts

Construction contracts establish the legal relationship between project parties by defining the scope of work, payment terms, project timelines, technical specifications, risk allocation, and dispute resolution procedures. Well-drafted contracts provide certainty, allocate responsibilities fairly, and reduce the risk of future disputes.

Regulatory Compliance

Construction projects must comply with federal legislation as well as Emirate-specific regulations, building codes, licensing requirements, health and safety standards, and environmental obligations. Failure to meet these requirements may result in project delays, financial penalties, contractual claims, or regulatory enforcement.

Risk Allocation

Every construction project involves commercial and legal risks, including cost overruns, design changes, unforeseen site conditions, delays, and contractor performance issues. Effective construction contract law allocates these risks between the parties through clearly defined contractual obligations, insurance requirements, performance securities, and liability provisions.

Construction Claims and Dispute Resolution

When unexpected events affect project performance, parties may submit construction claims seeking additional time, compensation, or other contractual relief. If claims cannot be resolved through negotiation, disputes may proceed to mediation, arbitration, or litigation, depending on the contract and applicable law.

Defects Liability and Decennial Liability

Contractors remain responsible for remedying defects identified during the contractual defects liability period. In addition, UAE law imposes mandatory decennial liability, making contractors and, in many cases, architects jointly liable for ten years for total or partial structural collapse or serious defects affecting the stability or safety of a building.

Legal Framework for UAE Construction

The UAE construction industry operates under a comprehensive legal framework combining federal legislation, Emirate-level regulations, and internationally recognised contractual standards. Construction projects are primarily governed by the UAE Civil Transactions Law, supported by local regulations and widely used FIDIC contracts, which are adapted to comply with mandatory provisions of UAE law. Understanding this framework helps businesses manage legal obligations, reduce contractual risk, and maintain compliance throughout the project lifecycle.

UAE Civil Transactions Law

The UAE Civil Transactions Law forms the foundation of construction law by regulating contracts for work (Muqawala), contractual rights and obligations, liability, breach of contract, and available legal remedies. Federal Decree-Law No. 25 of 2025, which came into force on 1 June 2026, modernised the UAE’s civil law framework while preserving the key principles governing construction contracts and commercial relationships.

Local Emirate Laws and Regulations

In addition to federal legislation, each Emirate applies its own construction regulations covering licensing, building approvals, inspections, and technical standards. For example, Dubai Law No. 7 of 2025 introduced a unified registration and contractor classification framework across Dubai, including free zones, while strengthening documentation, compliance, and project record-keeping requirements.

FIDIC Contracts in the UAE

FIDIC contracts remain the industry standard for many large-scale construction and infrastructure projects across the UAE. These internationally recognised contract forms provide structured procedures for project administration, payment, variations, delay claims, and dispute resolution. Although widely adopted, they are typically amended through Particular Conditions to ensure compliance with mandatory provisions of UAE construction law.

Decennial Liability (Article 880)

One of the most significant legal protections under UAE construction law is decennial liability. Under Article 880 of the Civil Transactions Law, contractors and architects may be jointly liable for ten years following project completion if a building suffers total or partial collapse or a serious structural defect that threatens its stability or safety. This statutory obligation cannot generally be excluded by agreement, making it a critical consideration when drafting and negotiating construction contracts.

What Does a Construction Lawyer Do?

A construction lawyer provides legal advice throughout every stage of a construction project, helping clients manage contractual risks, comply with UAE regulations, and resolve disputes efficiently. Construction lawyers advise on contract drafting and negotiation, regulatory compliance, payment disputes, construction defects, project delays, and dispute resolution for developers, contractors, consultants, architects, engineers, and property owners. Their role is not limited to disputes—they help prevent legal issues before they arise.

From reviewing tender documents and negotiating commercial contracts to advising on variations, extensions of time, and construction claims, a construction law attorney works to protect clients’ commercial interests while ensuring compliance with applicable laws and contractual obligations.

Does My Business Need a Construction Lawyer?

Businesses involved in construction projects can benefit from legal advice long before a dispute arises. Companies that negotiate construction contracts, manage subcontractors, or undertake complex development projects often require legal support to reduce financial risk, maintain regulatory compliance, and protect their contractual rights. Early legal involvement helps identify potential issues before they develop into costly claims or litigation.

A construction lawyer can assist with drafting and reviewing contracts, negotiating commercial terms, advising on risk allocation, managing payment and delay issues, handling construction defects, and representing clients during arbitration or court proceedings. Whether you are a developer, contractor, consultant, investor, or supplier, obtaining timely legal advice can improve project certainty and strengthen your legal position throughout the construction lifecycle.

Legal Considerations Throughout a Construction Project

Every stage of a construction project carries legal responsibilities that can affect cost, timelines, and project success. Managing legal considerations from project planning through final handover helps minimise contractual risk, maintain regulatory compliance, and reduce the likelihood of future disputes. A proactive legal strategy ensures that contracts remain enforceable, documentation is properly maintained, and obligations are fulfilled throughout the project.

Planning, Tendering & Contract Formation

The legal foundation of every project is established before construction begins. During this stage, parties define project requirements, prepare tender documents, evaluate procurement options, negotiate commercial terms, and draft construction contracts that clearly allocate risks and responsibilities. Proper contract formation helps prevent misunderstandings and supports successful project delivery.

Project Execution & Contract Administration

Once construction begins, effective contract administration becomes essential. Parties must comply with contractual obligations, issue site instructions, manage variations and change orders, maintain accurate project documentation, monitor performance, and respond promptly to emerging construction claims. Good record-keeping is often critical if disputes arise later.

Project Completion & Post-Completion Obligations

Completion marks an important legal milestone rather than simply the end of construction. Final inspections, handover documentation, testing, certification, and contract completion procedures determine when responsibility transfers to the employer. This stage also triggers the defects liability period, release of retention amounts where applicable, and the commencement of statutory obligations such as decennial liability, making careful legal compliance essential even after practical completion.

Types of Construction Contracts in the UAE

Selecting the right construction contract is one of the most important legal decisions at the start of any project. The contract determines how risks, responsibilities, pricing, timelines, variations, and dispute resolution will be managed throughout the project lifecycle. Under UAE construction law, parties are generally free to agree on the terms of their construction contracts, provided they comply with mandatory provisions of the UAE Civil Transactions Law and other applicable legislation.

The UAE construction industry commonly uses several contract models depending on the project’s size, complexity, procurement method, and risk allocation. Internationally recognized FIDIC contracts are also widely adopted, particularly for large commercial and infrastructure developments.

Lump Sum (Fixed Price) Contracts

A lump sum contract requires the contractor to complete an agreed scope of work for a fixed contract price. Since the contractor assumes most of the financial risk associated with cost increases, these contracts work best when the design and project specifications are substantially complete before construction begins.

This approach provides greater cost certainty for employers while encouraging contractors to carefully price the project from the outset. However, changes to the agreed scope usually require formal variation procedures and may result in additional costs or extensions of time.

Unit Price Contracts

Under a unit price contract, payment is based on the actual quantities of work completed using agreed unit rates set out in a Bill of Quantities (BoQ). Rather than paying a fixed overall price, the final contract value depends on the quantities measured during construction.

These contracts are frequently used for infrastructure, roadworks, utilities, and excavation projects where the exact quantities cannot be accurately determined before work begins. While the employer generally bears the risk of quantity changes, contractors remain responsible for performing the work efficiently at the agreed rates.

Cost-Plus Contracts

In a cost-plus contract, the employer reimburses the contractor for actual project costs together with an agreed management fee or profit percentage. Because the total project cost cannot be determined at the outset, the employer assumes a greater share of the financial risk.

Cost-plus arrangements are commonly used for urgent, complex, or fast-track projects where construction must begin before the final design has been completed. Strong cost controls, transparent reporting, and careful contract administration are essential to avoid disputes over reimbursable expenses.

FIDIC Standard Forms

The International Federation of Consulting Engineers (FIDIC) publishes internationally recognised standard forms that are widely used throughout the UAE construction industry. Although based on global best practices, these contracts are typically amended through Particular Conditions to comply with mandatory provisions of UAE law and the commercial objectives of the parties.

The most common FIDIC contracts used in the UAE include:

• Red Book: Suitable where the employer provides the design and the contractor is responsible for construction.
• Yellow Book: Commonly used for design-build projects where the contractor undertakes both design and construction.
• Silver Book: Designed for EPC and turnkey projects where the contractor assumes extensive responsibility for design, procurement, construction, testing, and delivery.

Proper selection and modification of the appropriate FIDIC contract can significantly reduce legal risk, improve project administration, and minimise future construction claims and contractual disputes.

Essential Contract Clauses

Well-drafted construction contracts reduce uncertainty, allocate risk fairly, and provide a clear framework for managing projects from commencement to completion. While every project has unique commercial requirements, certain contractual provisions are fundamental to protecting the interests of both employers and contractors under UAE construction law.

Scope of Work

The contract should clearly define the work to be performed, technical specifications, project deliverables, and each party’s responsibilities. A well-defined scope helps prevent misunderstandings, variation disputes, and disagreements over performance.

Payment Terms

Payment provisions should specify the contract price, payment schedule, certification procedures, retention amounts, and the consequences of late or non-payment. Clear financial terms help maintain project cash flow and reduce the risk of payment disputes.

Project Timeline

The agreement should establish commencement dates, completion milestones, extension of time (EOT) procedures, and obligations relating to project delays. Defining these timelines promotes accountability and provides a basis for evaluating delay-related claims.

Variations

Construction projects frequently require changes to the original scope. Variation clauses should explain how changes are instructed, valued, approved, and documented to minimise disputes over additional work or revised project costs.

Risk Allocation

Contracts should allocate responsibility for delays, unforeseen events, design obligations, insurance requirements, and site risks. Clearly assigning risk enables both parties to understand their contractual responsibilities before work begins.

Defects and Liability

The contract should address defect rectification procedures, warranty obligations, and statutory responsibilities, including decennial liability where applicable. These provisions help ensure construction defects are identified and remedied in accordance with UAE law.

Dispute Resolution

Every construction contract should specify how disputes will be resolved, whether through negotiation, mediation, construction law and arbitration, or litigation. Identifying the governing law, jurisdiction, and dispute resolution procedure helps avoid uncertainty if disagreements arise.

Construction Claims in the UAE

Construction claims are formal requests made by contractors or employers seeking additional time, financial compensation, or other contractual relief when project circumstances affect contractual performance. These claims commonly result from variations, unforeseen site conditions, design changes, delays, or other events that alter the original obligations. Their success largely depends on complying with contractual notice requirements, demonstrating a clear link between the event and its impact, and maintaining accurate project records throughout the construction process.

Unlike construction disputes, claims are a normal part of project administration and are intended to resolve contractual issues before they escalate into arbitration or litigation. Proper claim management protects contractual rights, supports commercial relationships, and can significantly reduce the likelihood of formal dispute resolution.

Types of Claims

The type of claim depends on the circumstances affecting the project. Common construction claims in the UAE include:

• Extension of Time (EOT) claims arising from delays beyond the contractor’s control.
• Variation claims resulting from changes to the agreed scope of work.
• Payment claims for unpaid certified work, interim payments, or outstanding invoices.
• Loss and expense claims seeking compensation for additional costs caused by project disruptions.
• Defect claims relating to defective workmanship, materials, or design responsibilities.
• Disruption and acceleration claims where project sequencing or employer instructions increase costs or reduce productivity.

What to Include in the Claim?

A well-prepared construction claim should be supported by clear evidence and comply with both the contract and applicable legal requirements. Depending on the circumstances, a claim should typically include:

• A clear description of the event giving rise to the claim.
• The relevant contractual provisions supporting the entitlement.
• Evidence demonstrating cause and effect.
• Project records, correspondence, site instructions, and supporting documentation.
• Details of the additional time or financial compensation being claimed.
• Confirmation that all contractual notice requirements and submission deadlines have been satisfied.

Governing Law and Jurisdiction in Construction Contracts

Before signing a construction contract, parties should decide which law governs the agreement and how future disputes will be resolved. These provisions determine which legal rules apply to the contract, where proceedings will take place, and how judgments or arbitral awards will be enforced.

Making these decisions at the outset provides greater legal certainty, reduces jurisdictional disputes, and allows parties to select a dispute resolution process that reflects the size, complexity, and commercial objectives of the project.

Choosing the Governing Law

The governing law is the legal system used to interpret the construction contract and determine each party’s rights and obligations. For projects carried out in the UAE, contracts are commonly governed by UAE law, including the Civil Transactions Law and other mandatory construction-related legislation.

For cross-border developments, parties may agree to apply another governing law where permitted. However, mandatory provisions of UAE legislation—particularly those relating to public policy and statutory liabilities such as decennial liability—may still apply regardless of the chosen governing law.

Choosing the Right Dispute Resolution Forum

The contract should also identify where disputes will be resolved. Depending on the project and the parties involved, disputes may be referred to UAE courts, arbitration, or specialist jurisdictions where available.

Projects involving international businesses or transactions connected with the DIFC legal system may choose the DIFC Courts as the dispute resolution forum, provided the jurisdictional requirements are satisfied. Selecting the appropriate forum at the contract stage helps avoid costly jurisdictional challenges if a dispute later arises.

Understanding the DIFC Legal System?

Learn how the Dubai International Financial Centre (DIFC) operates, how the DIFC legal system differs from the UAE mainland, and when businesses can choose DIFC law and DIFC Courts for commercial and construction contracts.

Read Our DIFC Guide

Common Construction Disputes

Even well-managed construction projects can encounter contractual disagreements. Most disputes arise when parties interpret their obligations differently, fail to meet contractual deadlines, or disagree over payment, quality, or changes to the scope of work.

The most common construction disputes in the UAE include:

Payment Disputes

Disagreements over interim payments, certified amounts, retention sums, unpaid invoices, or final account settlements remain among the most frequent construction disputes.

Project Delays

Delays caused by late approvals, design changes, unforeseen site conditions, labour shortages, or supply chain disruptions often result in claims for extensions of time and additional costs.

Variations and Scope Changes

Construction projects frequently evolve after work begins. Disputes may arise where additional work is instructed without following the contractual variation procedure or where parties disagree on valuation.

Defective Workmanship

Claims relating to defective construction, poor workmanship, non-compliant materials, or design deficiencies may arise during construction or after project completion, including claims involving statutory decennial liability.

Contract Termination

Early termination of a construction contract may result in disputes regarding outstanding payments, project completion, damages, or entitlement to terminate under the contract.

Professional Negligence

Contractors, consultants, architects, and engineers may face claims where professional errors, omissions, or failures contribute to project defects, delays, or financial losses.

Resolving Construction Disputes: Arbitration vs Litigation

When negotiations fail, construction disputes are generally resolved through either arbitration or litigation. The most suitable approach depends on the contract, the complexity of the dispute, the value of the claim, and the parties’ commercial objectives.

Construction Arbitration

Construction arbitration is widely used in the UAE to resolve high-value and technically complex construction disputes. Governed by the UAE Arbitration Law (Federal Law No. 6 of 2018) together with the applicable provisions of the Civil Transactions Law, arbitration commonly deals with claims involving project delays, extension of time (EOT), variations, defects, payment disputes, and other contractual issues arising under construction contracts.

Working with experienced arbitration lawyers helps parties prepare their claims, manage technical evidence, navigate arbitral procedures, and enforce arbitral awards. Arbitration also allows parties to appoint specialist arbitrators, maintain confidentiality, and benefit from greater procedural flexibility than traditional court proceedings. It is particularly common where FIDIC contracts contain arbitration clauses or where international parties require a neutral dispute resolution process.

Construction Litigation

Construction litigation involves resolving disputes before the UAE courts under the Civil Transactions Law (Federal Decree-Law No. 25 of 2025) and other applicable legislation governing Contracts for Work (Muqawala). Court proceedings commonly involve payment disputes, project delays, construction defects, contract termination, and statutory liabilities, including the mandatory ten-year decennial liability. Technical issues are frequently examined by court-appointed engineering experts whose reports often play a significant role in the court’s final judgment.

Experienced litigation lawyers represent clients throughout court proceedings, from preparing legal claims and presenting evidence to handling expert reports, appeals, and enforcement of judgments. Litigation may be the most appropriate option where no valid arbitration agreement exists, urgent court remedies are required, or the dispute falls within the jurisdiction of the UAE courts.

Looking for Trusted Legal Services in the UAE?

Al Ramsy Advocates & Legal Consultancy provides comprehensive legal services for businesses and individuals, including corporate law, litigation, arbitration, construction law, employment law, contract law, debt recovery, real estate, and other legal matters across the UAE.

Explore Our Legal Services

Choosing the Right Dispute Resolution Method

There is no single dispute resolution method that suits every construction project. Arbitration is often preferred for complex commercial developments because of its flexibility, confidentiality, and access to specialist decision-makers, while litigation may be more appropriate where immediate court intervention or statutory remedies are required.

The best option depends on the contract terms, the nature of the dispute, enforcement considerations, project value, and the parties involved. Understanding the differences between arbitration vs litigation before signing a construction contract can help parties select the most appropriate dispute resolution mechanism and avoid unnecessary procedural challenges later.

When Should You Consult a Construction Lawyer?

Construction projects involve significant financial investment, multiple stakeholders, and complex contractual obligations. Seeking legal advice early can help prevent disputes, reduce project risks, and protect your commercial interests before problems become more difficult and costly to resolve.

You should consider consulting a construction lawyer before signing a major construction contract, when project delays or construction defects arise, or as soon as payment disputes begin to develop. Legal advice is also valuable when dealing with contract variations, permit or regulatory compliance issues, termination notices, defective workmanship claims, or potential arbitration or litigation. Addressing legal issues promptly often provides more options for resolving disputes efficiently and protecting your contractual rights.

Why Choose Al Ramsy Advocates for Construction Law Matters?

Construction projects require legal advice that combines contractual knowledge with practical dispute resolution experience. At Al Ramsy Advocates & Legal Consultancy, we assist developers, contractors, consultants, subcontractors, investors, and property owners throughout every stage of a construction project—from contract drafting and risk management to construction claims, arbitration, and litigation.

Our team provides practical, commercially focused legal solutions tailored to the UAE construction industry, helping clients minimise risk, resolve disputes efficiently, and protect their long-term business interests.

• Extensive experience advising on UAE construction law and complex construction contracts.
• Comprehensive support from contract drafting and negotiation through project completion.
• Representation in construction claims, arbitration, and court proceedings.
• Experience handling FIDIC contracts, commercial contracts, and infrastructure projects.
• Strategic advice on risk allocation, regulatory compliance, and dispute prevention.
• Bilingual legal services for both domestic and cross-border construction matters.

Frequently Asked Questions

What is construction law in the UAE?

Construction law in the UAE is the body of laws governing construction projects from planning and contracting to project completion and dispute resolution. It regulates construction contracts, contractor obligations, project delivery, payment rights, liability for defects, and legal remedies available when contractual obligations are not fulfilled.

Which standard contracts are used in UAE construction projects?

The most widely used standard forms are the FIDIC contracts, particularly on commercial, infrastructure, and engineering projects. These contracts are typically amended through Particular Conditions to comply with mandatory provisions of UAE law and the specific commercial requirements of the project.

Which FIDIC contract is commonly used on UAE construction projects?

The most commonly used FIDIC contracts are the Red Book for employer-designed projects, the Yellow Book for design-build projects, and the Silver Book for EPC and turnkey developments. The appropriate form depends on the project’s procurement method and allocation of design responsibility.

How are construction disputes resolved in the UAE?

Construction disputes are commonly resolved through negotiation, mediation, arbitration, or litigation. The appropriate method depends on the dispute resolution clause in the construction contract, the nature of the dispute, and the parties’ commercial objectives.

Can a contractor be terminated before completing a project in the UAE?

Yes. A contractor may be terminated where the contract permits termination or where UAE law provides legal grounds for doing so. However, termination should always follow the contractual procedures and applicable legal requirements to minimise the risk of wrongful termination claims.

Can a contractor claim compensation for project delays in the UAE?

Yes. Contractors may be entitled to claim an extension of time, additional costs, or financial compensation where delays result from employer instructions, approved variations, unforeseen events, or other circumstances recognised under the construction contract and applicable law.

What is decennial liability in UAE construction law?

Decennial liability is a mandatory legal obligation that makes contractors and architects jointly liable for ten years for the total or partial collapse of a building or any structural defect that threatens its stability or safety, regardless of contractual provisions attempting to exclude that liability.

Who is responsible under decennial liability in the UAE?

In most cases, both the contractor and the supervising architect are jointly responsible for qualifying structural defects under the UAE Civil Transactions Law. Depending on the circumstances, liability may also extend to others involved in the design or execution of the project.

Are FIDIC contracts mandatory in the UAE?

No. FIDIC contracts are not legally mandatory, but they are widely adopted across the UAE construction industry because they provide internationally recognised contractual frameworks. Most projects modify the standard FIDIC terms to comply with UAE law and the parties’ commercial requirements.

What are the essential elements of a construction contract?

A well-drafted construction contract should clearly define the scope of work, project specifications, payment terms, timelines, variation procedures, risk allocation, defect liability, insurance requirements, governing law, and dispute resolution mechanism. Clear contractual terms help reduce uncertainty and minimise future disputes.

Conclusion

Construction projects involve significant financial commitments, complex contractual relationships, and evolving legal obligations throughout every stage of the project lifecycle. Understanding construction law in the UAE helps developers, contractors, consultants, and property owners manage risk, comply with legal requirements, and resolve issues before they develop into costly disputes.

Whether you need assistance drafting construction contracts, managing construction claims, addressing construction defects, or resolving disputes through arbitration or litigation, obtaining legal advice at an early stage can protect both your project and your commercial interests. At Al Ramsy Advocates & Legal Consultancy, our construction lawyers provide practical legal solutions tailored to the UAE construction sector, helping clients navigate complex projects with confidence and achieve successful outcomes.